Welcome to Villa Renovation Dubai. These Terms of Service govern your access to and use of our website and renovation services. By visiting our website, contacting us, or engaging our services, you agree to comply with and be bound by these Terms.
If you do not agree with any part of these Terms, please do not use our website or services.
1. About Villa Renovation Dubai
Villa Renovation Dubai is a Dubai-based interior fitting and renovation contractor providing services including villa renovation, home renovation, apartment renovation, office renovation, kitchen and bathroom remodeling, interior and exterior works, MEP services, and turnkey renovation solutions across Dubai, United Arab Emirates.
2. Scope of Services
All services are provided based on:
- Agreed project scope
- Written quotation or contract
- Approved drawings or specifications
Services may vary depending on property type, site conditions, approvals, and client requirements. Any work outside the agreed scope is considered a variation.
3. Use of Website
The information provided on this website is for general informational purposes only.
You agree not to:
- Misuse the website or its content
- Attempt unauthorized access to the website
- Copy, reproduce, or distribute website content without written permission
We reserve the right to modify or discontinue website content at any time.
4. Quotations, Estimates & Pricing
- All quotations and estimates are based on information available at the time of assessment.
- Online or verbal estimates are indicative and subject to change after site inspection.
- Final pricing is confirmed only through a written quotation or agreement.
Additional work, material changes, or scope variations may result in revised costs.
5. Payments & Billing
- Payment terms and schedules will be clearly stated in the quotation or agreement.
- Payments must be made according to the agreed schedule.
- Failure to make payments on time may result in work delays or suspension.
All prices are exclusive or inclusive of taxes as specified in the agreement.
6. Project Timelines & Delays
Project timelines are estimated based on:
- Scope of work
- Material availability
- Authority approvals
- Site access
Villa Renovation Dubai is not responsible for delays caused by factors beyond reasonable control, including approval delays, supply issues, client-requested changes, or force majeure events.
7. Approvals & Permissions
Certain renovation works may require approvals from Dubai Municipality, developers, or building management.
- Assistance with approvals may be included where agreed.
- Approval timelines are subject to authority processes and are not guaranteed.
Work may not proceed until required approvals are obtained.
8. Materials & Workmanship
- Materials will be supplied as specified in the approved quotation or agreement.
- Equivalent materials may be used if original selections are unavailable, subject to client approval.
- Natural variations in materials such as stone, wood, or tiles may occur.
Workmanship is delivered in accordance with standard industry practices.
9. Client Responsibilities
Clients are responsible for:
- Providing clear project requirements
- Ensuring site access during agreed working hours
- Securing personal belongings and valuables
Delays caused by restricted access or incomplete information may affect timelines.
10. Warranties & Liability
- Any warranties on workmanship or materials will be stated in the project agreement.
- Villa Renovation Dubai is not responsible for damage caused by misuse, lack of maintenance, or third-party modifications after project completion.
Liability is limited to the value of services provided under the agreement.
11. Third-Party Services
Some services may involve third-party suppliers, manufacturers, or specialists.
Villa Renovation Dubai is not responsible for the independent actions, warranties, or delays of third-party providers unless explicitly stated in writing.
12. Intellectual Property
All website content, including text, images, logos, designs, and branding, is the intellectual property of Villa Renovation Dubai unless otherwise stated.
Unauthorized use or reproduction is prohibited.
13. Termination of Services
Either party may terminate services in accordance with the terms outlined in the project agreement.
Any completed work and outstanding payments remain payable upon termination.
14. Privacy
Use of our website and services is also governed by our Privacy Policy, which explains how personal information is collected and handled.
15. Governing Law & Jurisdiction
These Terms of Service are governed by the laws of the United Arab Emirates.
Any disputes shall be subject to the exclusive jurisdiction of the courts of Dubai.
16. Changes to These Terms
Villa Renovation Dubai reserves the right to update or modify these Terms of Service at any time.
Continued use of our website or services indicates acceptance of the updated terms.
17. Contact Information
For questions regarding these Terms of Service, please contact:
Villa Renovation Dubai
📞 Phone: 0542878917
💬 WhatsApp: https://wa.me/971568513712
🌐 Website: https://villarenovation-dubai.com